88R2254 AJA-F     By: King S.B. No. 939       A BILL TO BE ENTITLED   AN ACT   relating to statutes of limitation and repose for certain claims   arising out of residential construction.          BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF TEXAS:          SECTION 1.  Section 16.008, Civil Practice and Remedies   Code, is amended by amending Subsections (a) and (c) and adding   Subsections (a-2) and (a-3) to read as follows:          (a)  Except as provided by Subsection (a-1) or (a-2), a   person must bring suit for damages for a claim listed in Subsection   (b) against a registered or licensed architect, engineer, interior   designer, or landscape architect in this state, who designs, plans,   or inspects the construction of an improvement to real property or   equipment attached to real property, not later than 10 years after   the substantial completion of the improvement or the beginning of   operation of the equipment in an action arising out of a defective   or unsafe condition of the real property, the improvement, or the   equipment.          (a-2)  With respect to any claim arising out of the design,   planning, or inspection of a new residence, of an alteration of or   repair or addition to an existing residence, or of an appurtenance   to a residence, a person must bring suit for damages for a claim   listed in Subsection (b) against a registered or licensed   architect, engineer, interior designer, or landscape architect in   this state, who designs, plans, or inspects the construction of an   improvement to real property or equipment attached to real   property, not later than eight years after the substantial   completion of the improvement or the beginning of operation of the   equipment in an action arising out of a defective or unsafe   condition of the real property, the improvement, or the equipment.          (a-3)  For purposes of Subsection (a-2), "residence" has the   meaning assigned by Section 27.001, Property Code.          (c)  If the claimant presents a written claim for damages,   contribution, or indemnity to the architect, engineer, interior   designer, or landscape architect within the applicable limitations   period, the period is extended for:                (1)  two years from the date the claim is presented, for   a claim to which Subsection (a) applies; or                (2)  one year from the date the claim is presented, for   a claim to which Subsection (a-1) or (a-2) applies.          SECTION 2.  Section 16.009, Civil Practice and Remedies   Code, is amended by amending Subsections (a) and (c) and adding   Subsections (a-2), (a-3), and (a-4) to read as follows:          (a)  Except as provided by Subsection (a-1) or (a-2), a   claimant must bring suit for damages for a claim listed in   Subsection (b) against a person who constructs or repairs an   improvement to real property not later than 10 years after the   substantial completion of the improvement in an action arising out   of a defective or unsafe condition of the real property or a   deficiency in the construction or repair of the improvement.          (a-2)  Except as provided by this subsection, with respect to   any claim arising out of the design, construction, or repair of a   new residence, of an alteration of or repair or addition to an   existing residence, or of an appurtenance to a residence, a   claimant must bring suit for damages for a claim listed in   Subsection (b) against a person who constructs or repairs an   improvement to real property not later than eight years after the   substantial completion of the improvement in an action arising out   of a defective or unsafe condition of the real property or a   deficiency in the construction or repair of the improvement. If the   person being sued is a contractor who has provided a written   warranty for the residence that complies with Subsection (a-3), the   claimant must bring the suit not later than five years after the   substantial completion of the improvement.          (a-3)  For purposes of Subsection (a-2), a written warranty   must provide a minimum period of:                (1)  one year for workmanship and materials;                 (2)  two years for plumbing, electrical, heating, and   air-conditioning delivery systems; and                 (3)  five years for major structural components.          (a-4)  For purposes of Subsection (a-2), "contractor" and   "residence" have the meanings assigned by Section 27.001, Property   Code.          (c)  If the claimant presents a written claim for damages,   contribution, or indemnity to the person performing or furnishing   the construction or repair work during the applicable limitations   period, the period is extended for:                (1)  two years from the date the claim is presented, for   a claim to which Subsection (a) applies; or                (2)  one year from the date the claim is presented, for   a claim to which Subsection (a-1) or (a-2) applies.          SECTION 3.  (a)  Except as provided by this section, Section   16.008, Civil Practice and Remedies Code, as amended by this Act,   applies to a cause of action arising out of a design, plan, or   inspection of the construction of an improvement to real property   or equipment attached to real property that commences on or after   the effective date of this Act. Section 16.008, Civil Practice and   Remedies Code, as amended by this Act, does not apply to a cause of   action arising out of a design, plan, or inspection that commences   on or after the effective date of this Act under a contract entered   into before that date.          (b)  A cause of action arising out of a design, plan, or   inspection of the construction of an improvement to real property   or equipment attached to real property that commenced before the   effective date of this Act or arising out of a design, plan, or   inspection of the construction of an improvement to real property   or equipment attached to real property that commences on or after   the effective date of this Act under a contract entered into before   that date is governed by the law applicable to the cause of action   immediately before the effective date of this Act, and that law is   continued in effect for that purpose.          SECTION 4.  (a)  Except as provided by this section, Section   16.009, Civil Practice and Remedies Code, as amended by this Act,   applies to a cause of action arising out of the design,   construction, or repair of an improvement to real property that   commences on or after the effective date of this Act. Section   16.009, Civil Practice and Remedies Code, as amended by this Act,   does not apply to a cause of action arising out of the design,   construction, or repair of an improvement to real property that   commences on or after the effective date of this Act under a   contract entered into before that date.          (b)  A cause of action arising out of the design,   construction, or repair of an improvement to real property that   commenced before the effective date of this Act or arising out of   the design, construction, or repair of an improvement to real   property that commences on or after the effective date of this Act   under a contract entered into before that date is governed by the   law applicable to the cause of action immediately before the   effective date of this Act, and that law is continued in effect for   that purpose.          SECTION 5.  This Act takes effect immediately if it receives   a vote of two-thirds of all the members elected to each house, as   provided by Section 39, Article III, Texas Constitution.  If this   Act does not receive the vote necessary for immediate effect, this   Act takes effect September 1, 2023.